Reso 2022-3307 - Laserfiche WebLink

Home Browse Search

Contract Clauses for Solicitation 47QSMD20R0001 Refresh Number 9 Contract Number: GS-07F-0031W (e) Definitions. The clause at EAR 52.202-1, Definitions, is incorporated herein by reference (f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (g)Invoice. (1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include (i) Name and address of the Contractor; (ii) Invoice date and number; (iii) Contract number, line item number and, if applicable, the order number; (iv) Description, quantity, unit of measure, unit price and extended price of the items delivered; (v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on an Government bill of lading; (vi) Terms of any discount for prompt payment offered; (vii) Name and address of official to whom payment is to be sent; (viii) Name, title, and phone number of person to notify in event of defective invoice; and (ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract. (x) Electronic funds transfer (EFT) banking information. (A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract. (B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer System fbr Award Management, or 52.232-34, Payment by Electronic Funds Transfer�-Other Than System fbr Award Management), or applicable agency procedures. (C) EFT banking information is not required if the Government waived the requirement to pay by EFT. (2) The due date for making invoice payments by the designated payment office is the later of the following two events: Page:68 of 211