Laserfiche WebLink
<br />services satisfactorily performed pnor to the date of termination, as <br />provided in Paragraph 4 herein. <br /> <br />(ii.) Notwithstanding the foregoing, the Consultant shall not be relieved of <br />liability to the City for damages sustained by it by virtue of a breach of the <br />agreement by Consultant and the City may reasonably withhold payments <br />to Consultant for the purposes of set-off until such time as the exact <br />amount of damages due the City from the Consultant is determined. <br /> <br />B. TERMINATION FOR CONVENIENCE OF CITY. The City may, for its convenience <br />and without cause terminate the services then remaining to be performed at any time by given <br />written notice which shall become effective ten (10) days following receipt by Consultant. The <br />terms of Paragraphs A(i) and (ii) shall be applicable hereunder. <br /> <br />C. TERMINA TION FOR INSOLVENCY. The City also reserves the right to terminate the <br />remaining services to be performed in the event the Consultant is placed either in voluntary or <br />involuntary bankruptcy or makes any assignment for the benefit of creditors. <br /> <br />10. ASSIGNMENTS, TRANSFERS, SUBCONTRACTING. The Consultant shall not <br />subcontract, assign or transfer any work under this agreement with the prior written consent of <br />the City. Should the Consultant subcontract any services under this agreement, it shall be done <br />with continued liability for the Consultant. The Consultant shall remain responsible for services, <br />responsibilities and liabilities of the subcontractor or any person or entity acting under <br />Consultant. <br /> <br />11. TIME OF COMPLETION. The services to be rendered by the Consultant shall be <br />commenced upon execution of this contract and shall be completed within the time specified in <br />this agreement. A reasonable extension of time shall be granted in the event the work of the <br />Consultant is delayed or prevented by the City or by circumstances beyond the reasonable <br />control of the Consultant including weather conditions of acts of God which render the <br />performance of the Consultant's duty impracticable. <br /> <br />12. INSURANCE REQUIREMENTS. Consultant shall maintain workmen's compensation <br />insurance as required by Florida law and shall furnish a copy of insurance certificate to the City. <br /> <br />13. ARBITRATION. It is the intention of the parties that whenever possible, if a dispute or <br />controversy arises hereunder, then, such dispute or controversy shall be settled by arbitration in <br />accordance with the procedures, rules and regulations of the American Arbitration Association. <br />The decision rendered by the Arbitrator shall be final and binding upon the parties and judgment <br />upon the award rendered by the arbitrator may be entered in any court having jurisdiction. <br />Arbitration shall be held in Miami-Dade County, Florida. All costs of arbitration and attorneys' <br />fees incurred by the parties shall be paid by the non-prevailing party or, if neither party prevails <br />on the whole, each party shall be responsible for a portion of the costs of arbitration. And their <br />respective attorneys' fees as may be determined by the court on confirmation. <br /> <br />14. CONFIDENTIAL INFORMATION. The Consultant shall not, either during the term of <br />this Agreement or any time for a period of TEN (10) years subsequent to that date upon which <br />the Consultant shall leave the employment of the City for any reason whatsoever, disclose to any <br /> <br />3 <br /> <br />Employment Services Agreement - Choice Hire <br />