Specifications - Laserfiche WebLink

Home Browse Search

.~ 19. Time for Performance: Except as otherwise expressly provided for in this agreement, should the performance of any required by this agreement to be performed by either party be prevented or delayed by reason by any act of God, strike, lockout, labor trouble, inability to secure materials, or any other cause except financial inability not the fault of the party required to perform the act, the time for performance of the act will be extended for a period of time equivalent to the period of delay will be excused; provided, however, that nothing contained in this section shall exclude the prompt payment by either party as required by this agreement or the performance of any act rendered difficult or impossible solely because of the financial condition of the party required to perform the act. 20. Arbitration. It is the intention of the parties that whenever possible, if a dispute or controversy arises hereunder then such dispute or controversy shall be settled by arbitration in accordance with the procedures, rules and regulations of the American Arbitration Association. The decision rendered by the Arbitrator shall be final and binding upon the parties and judgment upon the award rendered by the arbitrator may be entered in any court having jurisdiction. Arbitration shall be held in Miami-Dade County, Florida. The non-prevailing party shall pay all costs of arbitration and attorneys' fees incurred by the parties or, if neither party prevails on the whole, each party shall be responsible for a portion of the costs of arbitration and their respective attorneys' fees as may be determined by the court on confirmation. 21. Confidential Information. The Contractor shall not, either during the term of this Agreement or any time for a period of Ten (10) years subsequent to that date upon which the Contractor shall leave the employment of the City for any reason whatsoever, disclose to any person or entity, other than in the discharge of the duties of the Contractor under this Agreement, any information which the City designates in writing as "confidential." As a violation by the Contractor of the provisions of this Section could cause irreparable injury to the City and there is no adequate remedy at law for such violation, the City shall have the right, in addition to any other remedies available to it at law or in equity, to enjoin the Contractor in a court of equity for violating such provisions. 22. Notices. All notices and communications hereunder shall be in writing and shall be deemed given when sent postage prepaid by registered or certified mail, return receipt requested and, if intended for City to City Manager, Rick Conner, with a copy to Hans Ottinot, City Attorney, City of Sunny Isles Beach, 18070 Collins Avenue, Sunny Isles Beach, Florida 33160, and, if intended for Contractor, shall be addressed to, 23. Governing Law. The validity of this Agreement and the interpretation and performance of all of its terms shall be construed and enforced in accordance with the laws of the State of Florida, without regard to principles of conflict of laws thereof. The location of any action or proceeding commenced under or pursuant to this Agreement shall be in Miami-Dade County, in the State of Florida. 24. Audit. The Contractor shall make available to the City or its representative all required financial records associated with the Agreement for a period of three (3) years. 25. Non-Discrimination. The Contractor agrees to comply with all local and state civil rights ordinances and with Title VI of the Civil Rights Act of 1984 as amended, Title VIII of the Civil Rights Act of 1968 as amended, Title I of the Housing and Community Development Act of 1974 as amended, Section 504 of the Rehabilitation Act of 1973, the Americans with Disabilities Act of 1990, the Age Discrimination Act of 1975, Executive Order 11063, and with 25